Supreme Court of India Judgements

46915 Judgements hosted as on 02/11/2025 - Search (FREE), Subscribe, Read & Download

Category: Arbitration

Arbitration

However, the non-service of a S. 21 notice on a person does not, by itself, preclude the arbitral tribunal from impleading that person if they are found to be a party to the arbitration agreement — The primary purpose of S. 21 relates to commencement and time-related aspects, while other functions like informing about claims or potential arbitrators are incidental.

Apr 20, 2025 sclaw

2025 INSC 507 SUPREME COURT OF INDIA DIVISION BENCH ADAVYA PROJECTS PVT. LTD. Vs. M/S VISHAL STRUCTURALS PVT. LTD. AND OTHERS ( Before : Pamidighantam Sri Narasimha and Manoj Misra,…

Arbitration

Arbitration and Conciliation Act, 1996 — Section 37 — Limited Scope of Judicial Interference in Arbitration Awards — The Court reiterated the limited scope of judicial interference in arbitration awards under Section 37 — The Court held that it could not interfere with the arbitral award unless there was a patent illegality or a violation of the terms of the contract — Since the arbitral tribunal had correctly applied Clause 49.5 and the appellant had accepted its terms, there was no ground for interference.

Feb 4, 2025 sclaw

2025 INSC 138 SUPREME COURT OF INDIA DIVISION BENCH M/S. C & C CONSTRUCTIONS LTD. Vs. IRCON INTERNATIONAL LTD. ( Before : Abhay S. Oka and Ujjal Bhuyan, JJ. )…

Arbitration

Arbitration and Conciliation Act, 1996 — Section 37 — Contractual clauses — Enforceability of Clause 49.5 of the General Conditions of Contract (GCC) — The Court upheld the validity and enforceability of Clause 49.5 of the GCC, which states that in the event of any failure or delay by the employer (respondent) in fulfilling its obligations under the contract, the contractor (appellant) is not entitled to claim damages or compensation — Instead, the contractor is only entitled to an extension of time to complete the work — The Court found that the appellant had repeatedly invoked Clause 49.5 to seek extensions of time and had accepted the terms of the clause by submitting undertakings not to make any claims other than escalation for the delays caused by the respondent — Therefore, the appellant was estopped from challenging the validity of Clause 49.5.

Feb 2, 2025 sclaw

2025 INSC 138 SUPREME COURT OF INDIA DIVISION BENCH M/S. C & C CONSTRUCTIONS LTD. Vs. IRCON INTERNATIONAL LTD. ( Before : Abhay S. Oka and Ujjal Bhuyan, JJ. )…

Arbitration

Arbitration and Conciliation Act, 1996 — Section 11(6) read with Section 11(9) —Dispute over a contractual agreement — The main issue is whether the contract was breached and if so, what remedies are available —The petitioner argues that the respondent failed to fulfill their obligations under the contract —The respondent contends that they met all contractual requirements and that any issues were due to the petitioner’s actions —The court ruled in favor of the petitioner, finding that the respondent breached the contract —The court based its decision on the evidence presented, which showed that the respondent did not meet the contractual terms —The court applied principles of contract law, focusing on the obligations and duties outlined in the agreement —The court awarded damages to the petitioner and ordered the respondent to fulfill their contractual obligations.

Oct 2, 2024 sclaw

2024 INSC 710 SUPREME COURT OF INDIA FULL BENCH AJAY MADHUSUDAN PATEL AND OTHERS — Appellant Vs. JYOTRINDRA S. PATEL AND OTHERS — Respondent ( Before : Dr. Dhananjaya Y.…

You missed

Acquittal

Penal Code, 1860 (IPC) — Sections 302, 449, 376, 394 — Appeal against High Court’s upholding of conviction and sentence — Case based on circumstantial evidence — Absence of direct evidence connecting appellant to offense — Falsely implicated — Prosecution failed to establish guilt beyond reasonable doubt — No scientific evidence linking appellant — Important witnesses not associated in investigation or produced in court — Appeal allowed, conviction and sentence set aside.

Nov 2, 2025 sclaw
Cheque Dishonour

Negotiable Instruments Act, 1881 — Section 138 — Dishonour of cheque — Quashing of proceedings — Cheques issued as security and not for consideration — Memorandum of Understanding (MOU) clearly stated cheques were for security purposes to show banks and not for deposit — Complainant failed to read the complete terms of MOU in isolation and misinterpreted it to claim cheques were converted into debt — Court empowered to consider unimpeachable documents at pre-trial stage to prevent injustice — Complaints under Section 138 NI Act liable to be quashed.

Nov 2, 2025 sclaw
General Insurance

Insurance Law — Fire Insurance — Accidental Fire — Cause of fire is immaterial if the insured is not the instigator and there is no fraud. The objective of fire insurance is to indemnify the insured against loss by fire.

Nov 2, 2025 sclaw
Tenders

Tender Conditions — Interpretation — Ambiguity — The terms of a tender must be clear and unambiguous — If a tendering authority intends for a specific document to be issued by a particular authority, it must be clearly stated in the tender conditions — Failure to do so may lead to rejection of the bid being deemed arbitrary and dehors the tender terms.

Nov 2, 2025 sclaw